Legals pg 11 12-12-19
- Details
- Category: Current Issue
Legal Notice
Town of Putnam
INVITATION TO BID
Notice to Contractors:
Sealed bids for the construction of the following project will be received by Office of Mayor, Putnam Town Hall at 126 Church Road, Putnam, CT 06260 until 11:00 a.m., January 9, 2020, after which time no further bids will be accepted. NO EXCEPTIONS. The bids will be publicly opened and read in the Daniel Rovero Selectman Chambers at 126 Church Road, Putnam, CT 06260.
FEDERAL PROJECT
F.A.P. #1115(106) Town of Putnam
State Project No. 115-120
Replacement of Bridge No. 04760, Woodstock Avenue #1 over Little River
Contract Goal: 11% Disadvantaged Business Enterprises (DBEs)
The Town of Putnam (Municipality) hereby notifies all bidders that it will affirmatively ensure that in any contract entered into pursuant to this advertisement, Disadvantaged Business Enterprises will be afforded full opportunity to submit bids in response to this invitation and that they will not be discriminated against on the grounds of race, color, national origin, sex, sexual orientation, mental retardation or physical disability, including but not limited to blindness, in consideration for an award.
“Bid Proposal Form”, “Schedule of Prices”, “Bid Bond”, “Non Collusion Affidavit” and “Bidder’s Prequalification approval letter signed by the CTDOT Contracts Manager must be completed and returned with the submitted bid. Failure to properly execute and include any one of these five documents in the bid submission will result in the bid not being read and the subsequent rejection of the bid.
Plans and Specifications for the above project may be examined and/or obtained at Advanced Reprographics, 50 Corporate Avenue, Plainville, CT 06062, (860) 410-1020. Plans and Specifications may be viewed and/or obtained by going to the Advanced Reprographics website www.advancedrepro.net. Prospective bidders should access the “Planroom” on the website and go to the “Public Jobs” area, no log in information is necessary. Plans and specifications may be picked up at the Advanced Reprographics office. Plans and specifications may also be ordered by calling the Advanced Reprographics number listed above. Bidders are responsible for all printing costs and shipping costs, as applicable.
Form 817 Standard Specifications and Supplemental Specifications may be obtained via the Connecticut Department of Transportation’s website: http://www.ct.gov/dot/cwp/view.asp?a=3609&q=430362. All Proposals must be on the form furnished by the Municipality and must be requested for the above named project.
NOTE: Prospective bidders must have a current sworn Statement (CON-16) on file with the Connecticut Department of Transportation and be prequalified to perform Group No. 9 (Intermediate Bridges) work. The Bidder’s Prequalification approval letter signed by the CTDOT Contracts Manager shall be included as part of the bid package submitted to the Municipality.
NOTE: Any Contractor or Subcontractor engaged in surface preparation and/or coating application must be certified by the Steel Structures Painting Council.
NOTE: A Surety Company Bond, on the form furnished by the Municipality, for at least 30 percent of the amount of the bid must accompany each proposal. A certified check will not be accepted. The Municipality reserves the right to reject any and all bids.
NOTE: The apparent low bidder, as determined by the Municipality immediately after the bid opening, shall submit the Pre-award DBE Commitment Approval Request form(s) to the Municipality NO LATER THAN FIVE (5) calendar days after the bid opening. This is a requirement of Title 49, Code of Federal Regulations (CFR) Part 26, Participation of DBEs.
NOTE: An optional pre-bid meeting will be held at 11:00 a.m. December 19th at the Daniel Rovero Selectman Chambers at 126 Church Road, Putnam, CT 06260.
CONTRACTORS that find discrepancies and/or errors in or between plans, specifications, quantities and other matters, must immediately notify WMC Consulting Engineers in writing not less than ten days before the scheduled bid opening.
Date: December 12, 2019
Town of Putnam
Legal Notice
STATE OF CONNECTICUT
Judicial District of Hartford at Hartford
Timothy T Brown, Plaintiff
Samantha M Brown, Defendant
Notice to Samantha M Brown
of parts unknown
A Complaint has been filed with this court that asks for divorce – dissolution of marriage with a return date of January 14, 2020.
You are named as a party in this case.
To participate in your case, you must file an Appearance, form JD-CL-12, with the court.
Failure to file an Appearance in accordance with the law of the State of Connecticut may result in judgment against you or granting of the relief requested by the party who filed the action or motion.
You may obtain the Appearance form from any Connecticut Judicial District Court Clerk’s Office, Court Service Center, or online at http://www.jud.ct.gov/webforms/forms/cl012.pdf
If this notice is to inform you of a divorce, dissolution of civil union, legal separation, annulment, custody, or visitation case, Automatic Court Orders have been issued in this case as required by section 25-5 of the Connecticut Practice Book and are a part of the Complaint on file with the Court.
A hearing on this matter has been scheduled for April 20, 2020, at 90 Washington Street, Hartford, CT.
By Judge Connors
Signed by Clerk Sarina Atilas
Date Signed 11/19/2019
Dec. 12, 2019
Dec. 19, 2019
Legal Notice
Town of Putnam
Zoning Commission
The Town of Putnam Zoning Commission will hold a meeting on December 18, 2019, at 7:00 P.M. at the Putnam Town Hall, located at 126 Church Street, Putnam, CT. A public hearing will be held on the following:
Docket # 2018-10: Rawson Materials, Madilyn Smith — Request for a Special Permit for gravel removal consisting of 43,000 cubic yards. Properties located at 10, 38, & 52 Cady Road, Town Assessor’s Map 34, Lots 77, 78 & 79. Zoned AG-2.
Patricia Hedenberg,
Chairman
Dec. 5, 2019
Dec. 12, 2019
..